If a labor harmony agreement had been in place before, Fishback said, management would not have been able to try to interfere with union efforts. A recourse provision also applies to the framework. If the project is not implemented under an employment contract, Multnomah County will first turn to the contractor to try to meet the minimum requirements. If this fails, there may be a breach of contract, followed by possible termination of the contract and reimbursement of the county`s associated costs. If the owner is responsible for providing non-unionized labour, the contractor should consider negotiating the main contract for time and cost increases in the event of a delay or disruption to the picket lines. However, if the contractor hires the non-unionized workers, the owner likely expects them to bear the risk of time and cost impacts due to delays or disruptions resulting from picket lines. Bills do not require a contract for harmony of work where the public body determines that the proposed project would not be able to proceed if such an agreement is required. Similarly, for the construction of the projects covered by the bills, no working harmony agreement is required. If an employee, visitor or supplier of the affected contractor uses the neutral door, the law also allows pickets at the neutral door. Contractors can reduce the likelihood of this event by requiring their subcontractors, through subcontracts, to (1) comply with all dual-door policies implemented in the workplace and (2) comply with the same work harmony obligations that the contractor has to the owner. “Today is an important step forward in Multnomah County`s commitment to continue and support labor harmony agreements,” said President Deborah Kafoury. “We will continue to learn from national models, with our partners and through our own experience of how to strengthen our efforts to build a stable workforce, deliver high-quality services and create prosperous communities.
The legislation requires employers with whom the state signs behavioral health and drug abuse contracts through the Department of Social Services and the Department of Children and Families to enter into social peace agreements. This ensures that workers who want to form a union can do so without fear of harassment and intimidation. Covid-19 highlights the urgency of the county after the harmony of work was first reviewed in 2017, and the agreement applies to the county`s Behavioral Health Division (BHD) and Early Learning and Early Childhood (PELD) Division, and eligibility applies to all their service requests except facilities and information technology. It would also apply to all contracts over $150,000. Council recognized the concerns of front-line workers and unanimously adopted an agreement on employee harmony. The agreement reaffirms the county`s commitment to having a stable and well-supported workforce and avoiding conflicts in work management and service interruptions. Commissioner Jessica Vega Pederson, who championed the Preschool For All initiative, said that harmonious work will be a key element from the start of the programme`s implementation. The Preschool Plan for All included specific provisions to strengthen the preschool workforce, including competitive wages and a living wage for teaching assistants. A work harmony agreement is the best tool the county has to ensure that these goals are achieved, she said.
Multnomah County began seeking a working harmony agreement in 2017 after AFSCME released a report titled “United We Heal,” which advocated for improved conditions for behavioral health workers. AFSCME Local 75 called on the county to pursue a “social peace agreement” that applies to behavioral health workers. The work harmony agreement has three fundamental objectives: to ensure the continuity of services to clients; recognize that these services require a stable workforce; Contractors and subcontractors should enter into work harmonic agreements for at least five years to work on eligible projects. As with many issues, those that involve harmonious work often begin with the owner-contractor agreement. Landlords are increasingly emphasizing work harmony provisions that require the contractor to fulfill the contract despite the appearance of picket lines and prohibit the contractor from obtaining additional time or money for delays or disruptions resulting from picket lines. Therefore, contractors need to understand their risks and know how to manage a mixed business project to minimize the risk of delays and disruptions. The agreement contains the following provisions: Contractors must certify the commitment to work in harmony and a negotiated project employment contract (PLA); The PLA – between contractors and workers – aims to minimize service interruptions, work stoppages and other economic problems affecting the operation of services. and if the PLA is not reached within 60 days, mediation and arbitration are required.
.